In re Miami Conservancy Dist.

Citations

• 2025 Ohio 116

Syllabus

Appellant, a contractor for a dam repair project, appealed from the trial court's grant of summary judgment to the conservancy district on the contractor's claims for additional payment on four payment items, as well as the conservancy district's claim for delay damages. The trial court properly granted summary judgment regarding the contractor's claim for additional payment for concrete patching and the conservancy district's delay claim. As to the remaining three payment items, genuine issues of material fact existed regarding the compensable amount of concrete. Judgment affirmed in part, reversed in part, and remanded.