Kinetic Builder's, Inc.,appellant v. F. Whitten Peters, Secretary of the Air Force,appellee

How courts have described this case

Verbatim parenthetical descriptions written by other courts when citing this decision. Ranked by citation-network relevance.

• recognizing and reviewing the ASBCA’s denial of a contractor’s claim for extended overhead costs incurred as a result of a delay in contract completion
• declining to award field overhead costs when contractor failed to show that government's actions affected the critical path
• \A project should be considered substantially completed when it is capable of being used for its intended purpose.\

Source: CourtListener parenthetical corpus (CC0).