Junta de Planificación de Puerto Rico v. Rodríguez Colom

How courts have described this case

Verbatim parenthetical descriptions written by other courts when citing this decision. Ranked by citation-network relevance.

• holding court may rely on other evidence in the record where plaintiffs total time theory has been rejected
• holding Government’s failure to install equipment in a timely manner breaches duty not to hinder
• placing burden on contractor to show that the work was delayed due to the lack of approval
• placing burden on contractor to show that the work was delayed due to the lack of approval
• noting it is the contractor's burden to show \where the work was delayed because of the lack of approval\
• government caused delay by failing to act on shop drawings and waiting too long to make permitted changes.

Source: CourtListener parenthetical corpus (CC0).