Hou-Ching Chou v. Wong

How courts have described this case

Verbatim parenthetical descriptions written by other courts when citing this decision. Ranked by citation-network relevance.

• \[W]hether the [owner] or other third parties may have contributed to some of the delay\ does not relieve the contractor from liability.
• “[W]hether the [owner] or other third parties may have contributed to some of the delay” does not relieve the contractor from liability.
• parties to construction contract impliedly agree not to hinder or obstruct other party’s performance
• “The delay and improper performance of the preparatory work by [defendant] ..., and not within the contemplation of the parties when their contract was executed, constituted a material breach of [defendant’s] implied obligation not to hinder or obstruct plaintiffs performance.”

Source: CourtListener parenthetical corpus (CC0).