E Solutions For Buildings, LLC v. Knestrick Contractors, Inc.

Syllabus

This is the third appeal in a dispute among a general contractor, a subcontractor, and an equipment supplier. Each party blamed the others for delays in a construction project. After the first appeal was dismissed for lack of a final judgment, the trial court held each party partially responsible for the delays and partially responsible for liquidated damages assessed by the owner. In the second appeal, this court modified the judgment in part, reversed it in part, and remanded for further proceedings. On remand, the subcontractor sought to recover from the general contractor discretionary costs of $10,962.42, attorneys' fees of $220,724.53 under the Prompt Pay Act of 1991, Tenn. Code Ann. §§ 66-34-101 to -704, and \[a]dditional charges.\ The trial court awarded some of the requested fees but excluded $100,350 of attorneys' fees attributed to legal services rendered during the first and second appeal because the subcontractor's request for appellate attorneys' fees was untimely, i.e., the relief had not been requested in the pleadings in the prior appeals. The trial court also denied $29,685 in fees incurred in the trial court proceedings for legal services that were \unrelated to [the general contractor].\ The trial court also found the subcontractor was not entitled to recover the \[a]dditional charges\ because the remand from the Court of Appeals did not authorize such expenses. This appeal followed. The principal issues in this appeal concern the subcontractor's claims for attorneys' fees and additional expenses and whether the general contractor's surety is secondarily liable for one of the judgments. Finding no error, we affirm the trial court's judgment in all respects.