Anthony Smith v. Ron Davis

How courts have described this case

Verbatim parenthetical descriptions written by other courts when citing this decision. Ranked by citation-network relevance.

• contract language stating contractor bears risk of delays due to utilities does not necessarily preclude contractor's recovery but what parties intended contract language to mean is a factual issue which prevents summary judgment
• contract language stating contractor bears risk of delays due to utilities does not necessarily preclude contractor’s recovery, but what parties intended contract language to mean is a factual issue which prevents summary judgment

Source: CourtListener parenthetical corpus (CC0).