Notice2025-20438
Agency Information Collection Activity: VAAR Construction Provisions and Clauses
Primary source
Metadata and text below are from the Federal Register, a public-domain U.S. government work. Always verify the official published version before relying on it for any legal matter.
Published
November 20, 2025
Issuing agencies
Veterans Affairs Department
Abstract
In compliance with the Paperwork Reduction Act (PRA) of 1995, this notice announces that the Office of Acquisition and Logistics (OAL), Department of Veterans Affairs (VA), will submit the collection of information abstracted below to the Office of Management and Budget (OMB) for review and comment. The PRA submission describes the nature of the information and its expected cost and burden, and it includes the actual data collection instrument.
Full Text
<html>
<head>
<title>Federal Register, Volume 90 Issue 222 (Thursday, November 20, 2025)</title>
</head>
<body><pre>
[Federal Register Volume 90, Number 222 (Thursday, November 20, 2025)]
[Notices]
[Page 52495]
From the Federal Register Online via the Government Publishing Office [<a href="http://www.gpo.gov">www.gpo.gov</a>]
[FR Doc No: 2025-20438]
-----------------------------------------------------------------------
DEPARTMENT OF VETERANS AFFAIRS
[OMB Control No. 2900-0422]
Agency Information Collection Activity: VAAR Construction
Provisions and Clauses
AGENCY: Office of Acquisition and Logistics, Department of Veterans
Affairs.
ACTION: Notice.
-----------------------------------------------------------------------
SUMMARY: In compliance with the Paperwork Reduction Act (PRA) of 1995,
this notice announces that the Office of Acquisition and Logistics
(OAL), Department of Veterans Affairs (VA), will submit the collection
of information abstracted below to the Office of Management and Budget
(OMB) for review and comment. The PRA submission describes the nature
of the information and its expected cost and burden, and it includes
the actual data collection instrument.
DATES: Comments and recommendations on the proposed information
collection should be sent by December 22, 2025.
ADDRESSES: To submit comments and recommendations for the proposed
information collection, please type the following link into your
browser: <a href="http://www.reginfo.gov/public/do/PRAMain">www.reginfo.gov/public/do/PRAMain</a>, select ``Currently under
Review--Open for Public Comments'', then search the list for the
information collection by Title or ``OMB Control No. 2900-0422.''
FOR FURTHER INFORMATION CONTACT: VA PRA information: Dorothy Glasgow,
202-461-1084, <a href="/cdn-cgi/l/email-protection#287e69787a69685e49064f475e"><span class="__cf_email__" data-cfemail="683e29383a29281e09460f071e">[email protected]</span></a>.
SUPPLEMENTARY INFORMATION:
Title: VAAR Construction Provisions and Clauses.
OMB Control Number: 2900-0422. <a href="https://www.reginfo.gov/public/do/PRASearch">https://www.reginfo.gov/public/do/PRASearch</a>.
Type of Review: Extension without change of a currently approved
collection.
Abstract: This Paperwork Reduction Act (PRA) submission seeks
renewal without changes of OMB approval No. 2900-0422 for five
collections of information for the Department of Veterans Affairs
Acquisition Regulation (VAAR) clauses, as follows:
<bullet> Clause 852.232-70, Payment Under Fixed-Price Construction
Contracts (without NAS-CPM), requires construction contractors not
using Network Analysis System-Critical Path Method (NAS-CPM), to submit
a schedule of costs for work to be performed under the contract.
<bullet> Clause 852.232-71, Payment Under Fixed-Price Construction
Contracts (including NAS-CPM), requires construction contractors using
NAS-CPM, to submit a schedule of costs for work to be performed under
the contract.
<bullet> Clause 852.236-72, Performance of Work by the Contractor,
requires contractors awarded a construction contract containing Federal
Acquisition Regulation clause 52.236-1, Performance of Work by the
Contractor, to submit a statement designating the branch or branches of
contract work to be performed by the contractor's own forces.
<bullet> Clause 852.236-80, Subcontracts and Work Coordination,
requires construction contractors, on contracts involving complex
mechanical-electrical work, to furnish coordination drawings showing
the manner in which utility lines will fit into available space and
relate to each other and to the existing building elements.
<bullet> Clause 852.243-70, Construction Contract Changes-
Supplement, requires contractors to submit cost proposals for changes
ordered by the contracting officer or for changes proposed by the
contractor.
An agency may not conduct or sponsor, and a person is not required
to respond to a collection of information unless it displays a
currently valid OMB control number. The Federal Register Notice with a
60-day comment period soliciting comments this collection of
information was published at 90 FR 44907, September 17, 2025.
Affected Public: Business or other for-profit.
Estimated Annual Burden: 2,974 hours.
Estimated Average Burden per Respondent: 105 minutes.
Frequency of Response: More than quarterly.
Estimated Number of Respondents: 1,706.
Authority: 44 U.S.C. 3501 et seq.
Dorothy Glasgow,
Acting, VA PRA Clearance Officer, Office of Information Technology,
Data Governance Analytics Department of Veterans Affairs.
[FR Doc. 2025-20438 Filed 11-19-25; 8:45 am]
BILLING CODE 8320-01-P
</pre><script data-cfasync="false" src="/cdn-cgi/scripts/5c5dd728/cloudflare-static/email-decode.min.js"></script></body>
</html>Indexed from Federal Register on November 20, 2025.
This is legal information, not legal advice. Laws vary by jurisdiction and change frequently. Always verify current law with official sources and consult a licensed attorney in your jurisdiction for advice on your specific situation.