Notice2024-05107
Submission for OMB Review; Certain Federal Acquisition Regulation Part 36 Construction Contract Requirements
Primary source
Metadata and text below are from the Federal Register, a public-domain U.S. government work. Always verify the official published version before relying on it for any legal matter.
Published
March 11, 2024
Issuing agencies
Defense DepartmentGeneral Services AdministrationNational Aeronautics and Space Administration
Abstract
Under the provisions of the Paperwork Reduction Act, the Regulatory Secretariat Division has submitted to the Office of Management and Budget (OMB) a request to review and approve a revision of a previously approved information collection requirement regarding certain Federal Acquisition Regulation (FAR) part 36 construction contract requirements.
Full Text
<html>
<head>
<title>Federal Register, Volume 89 Issue 48 (Monday, March 11, 2024)</title>
</head>
<body><pre>
[Federal Register Volume 89, Number 48 (Monday, March 11, 2024)]
[Notices]
[Pages 17469-17470]
From the Federal Register Online via the Government Publishing Office [<a href="http://www.gpo.gov">www.gpo.gov</a>]
[FR Doc No: 2024-05107]
=======================================================================
-----------------------------------------------------------------------
DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
[OMB Control No. 9000-0064; Docket No. 2024-0053; Sequence No. 1]
Submission for OMB Review; Certain Federal Acquisition Regulation
Part 36 Construction Contract Requirements
AGENCY: Department of Defense (DOD), General Services Administration
(GSA), and National Aeronautics and Space Administration (NASA).
ACTION: Notice.
-----------------------------------------------------------------------
SUMMARY: Under the provisions of the Paperwork Reduction Act, the
Regulatory Secretariat Division has submitted to the Office of
Management and Budget (OMB) a request to review and approve a revision
of a previously approved information collection requirement regarding
certain Federal Acquisition Regulation (FAR) part 36 construction
contract requirements.
DATES: Submit comments on or before April 10, 2024.
ADDRESSES: Written comments and recommendations for this information
collection should be sent within 30 days of publication of this notice
to <a href="http://www.reginfo.gov/public/do/PRAMain">www.reginfo.gov/public/do/PRAMain</a>. Find this particular information
collection by selecting ``Currently under Review--Open for Public
Comments'' or by using the search function.
FOR FURTHER INFORMATION CONTACT: Zenaida Delgado, Procurement Analyst,
at telephone 202-969-7207, or <a href="/cdn-cgi/l/email-protection#b8c2ddd6d9d1dcd996dcddd4dfd9dcd7f8dfcbd996dfd7ce"><span class="__cf_email__" data-cfemail="80fae5eee1e9e4e1aee4e5ece7e1e4efc0e7f3e1aee7eff6">[email protected]</span></a>.
SUPPLEMENTARY INFORMATION:
A. OMB Control Number, Title, and Any Associated Form(s)
9000-0064, Certain Federal Acquisition Regulation Part 36
Construction Contract Requirements.
B. Need and Uses
DoD, GSA, and NASA are combining OMB Control Nos. by FAR part. This
consolidation is expected to improve industry's ability to easily and
efficiently identify burdens associated with a given FAR part. This
review of the information collections by FAR part allows improved
oversight to ensure there is no redundant or unaccounted for burden
placed on industry. Lastly, combining information collections in a
given FAR part is also expected to reduce the administrative burden
associated with processing multiple information collections.
This justification supports the extension of OMB Control No. 9000-
0064 and combines it with the previously approved information
collection under OMB Control No. 9000-0062, with the new title
``Certain Federal Acquisition Regulation Part 36 Construction Contract
Requirements''. Upon approval of this consolidated information
collection, OMB Control No. 9000-0062 will be discontinued. The burden
requirements previously approved under the discontinued number will be
covered under OMB Control No. 9000-0064.
This clearance covers the information that contractors must submit
to comply with the following FAR requirements:
<bullet> FAR 52.236-5, Material and Workmanship. This clause
requires contractors to obtain contracting officer approval of the
machinery, equipment, material, or articles to be incorporated into the
work. The contractor's request must include: the manufacturer's name,
the model number, and other information concerning the performance,
capacity, nature, and rating of the machinery and mechanical and other
equipment; and full information concerning the material or articles.
When directed by the contracting officer, the contractor must submit
samples of the items requiring approval for incorporating into the
work. The contracting officer uses this information to determine
whether the machinery, equipment, material, or articles meet the
standards of quality specified in the contract. A contracting officer
may reject work, if the contractor installs machinery, equipment,
material, or articles in the work without obtaining the contracting
officer's approval.
<bullet> FAR 52.236-13, Accident Prevention, Alternate I. This
alternate to the basic clause requires contractors to submit a written
proposed plan to provide and maintain work environments and procedures
that will safeguard the public and Government personnel, property,
materials, supplies, and equipment exposed to contractor operations and
activities; avoid interruptions of Government operations and delays in
project completion dates; and control costs in the performance of this
contract. The plan must include an analysis of the significant hazards
to life, limb, and property inherent in
[[Page 17470]]
contract work performance and a plan for controlling these hazards. The
contracting officer and technical representatives analyze the Accident
Prevention Plan to determine if the proposed plan will satisfy the
safety requirements identified in the contract, to include certain
provisions of the Occupational Safety and Health Act (per FAR
36.513(c)) and applicable standards issued by the Secretary of Labor at
29 CFR part 1926 and 29 CFR part 1910.
<bullet> FAR 52.236-15, Schedules for Construction Contracts. This
clause requires contractors to prepare and submit to the contracting
officer for approval three copies of a practicable schedule showing the
order in which the contractor proposes to perform the work, and the
dates on which the contractor contemplates starting and completing the
several salient features of the work (including acquiring materials,
plant, and equipment). The contracting officer uses this information to
monitor progress under a Federal construction contract when other
management approaches for ensuring adequate progress are not used.
<bullet> FAR 52.236-19, Organization and Direction of the Work.
This clause requires contractors, under cost-reimbursement construction
contracts, to submit to the contracting officer a chart showing the
general executive and administrative organization, the personnel to be
employed in connection with the work under the contract, and their
respective duties. The contractor must keep the data furnished current
by supplementing it as additional information becomes available. The
contracting officer uses this information to ensure the work is
performed by qualified personnel at a reasonable cost to the
Government.
C. Annual Burden
Respondents: 3,771.
Total Annual Responses: 13,267.
Total Burden Hours: 21,338.
D. Public Comment
A 60-day notice was published in the Federal Register at 89 FR 786,
on January 5, 2024. No comments were received.
Obtaining Copies: Requesters may obtain a copy of the information
collection documents from the GSA Regulatory Secretariat Division, by
calling 202-501-4755 or emailing <a href="/cdn-cgi/l/email-protection#b4f3e7f5e6d1d3e7d1d7f4d3c7d59ad3dbc2"><span class="__cf_email__" data-cfemail="a6e1f5e7f4c3c1f5c3c5e6c1d5c788c1c9d0">[email protected]</span></a>. Please cite OMB
Control No. 9000-0064, Certain Federal Acquisition Regulation Part 36
Construction Contract Requirements.
Janet Fry,
Director, Federal Acquisition Policy Division, Office of Governmentwide
Acquisition Policy, Office of Acquisition Policy, Office of
Governmentwide Policy.
[FR Doc. 2024-05107 Filed 3-8-24; 8:45 am]
BILLING CODE 6820-EP-P
</pre><script data-cfasync="false" src="/cdn-cgi/scripts/5c5dd728/cloudflare-static/email-decode.min.js"></script></body>
</html>Indexed from Federal Register on March 11, 2024.
This is legal information, not legal advice. Laws vary by jurisdiction and change frequently. Always verify current law with official sources and consult a licensed attorney in your jurisdiction for advice on your specific situation.